Cases Decided in the Court of Claims of the United States, Volumen100U.S. Government Printing Office, 1944 |
Dentro del libro
Resultados 1-5 de 98
Página 16
... Claims has consistently held that neither Article 9 nor Article 15 of the Standard Government Construction Contract gives the contracting officer the power to determine finally a con- tractor's claim for damages for delay . See Phoenix ...
... Claims has consistently held that neither Article 9 nor Article 15 of the Standard Government Construction Contract gives the contracting officer the power to determine finally a con- tractor's claim for damages for delay . See Phoenix ...
Página 32
... claim he might have had therefor . The contracting officer several different times requested plaintiff to submit a ... claim to the 27 days ' delay . It may be that had he requested both the 27 days and the 24 days , the 24 days would ...
... claim he might have had therefor . The contracting officer several different times requested plaintiff to submit a ... claim to the 27 days ' delay . It may be that had he requested both the 27 days and the 24 days , the 24 days would ...
Página 38
... Claim for extra photographs . - Plaintiff claims the cost of taking photographs to sustain his claim for expenses incurred for erecting an exterior masonry scaffold and for removing and rebuilding the boiler pit . This is an expense of ...
... Claim for extra photographs . - Plaintiff claims the cost of taking photographs to sustain his claim for expenses incurred for erecting an exterior masonry scaffold and for removing and rebuilding the boiler pit . This is an expense of ...
Página 47
... claim in full . 6. In his income - tax return for 1937 , plaintiff included in gross income his share of the amounts ... claim for $ 28,270.17 with interest , based on the same grounds for recovery as are set forth in the petition in ...
... claim in full . 6. In his income - tax return for 1937 , plaintiff included in gross income his share of the amounts ... claim for $ 28,270.17 with interest , based on the same grounds for recovery as are set forth in the petition in ...
Página 69
... claim for an adjustment due to changed con- ditions also relates to this sand bar , so we shall discuss this claim now before taking up its other claim of misrepresenta- tion of the conditions at the site . Plaintiff says that a flood ...
... claim for an adjustment due to changed con- ditions also relates to this sand bar , so we shall discuss this claim now before taking up its other claim of misrepresenta- tion of the conditions at the site . Plaintiff says that a flood ...
Otras ediciones - Ver todas
Términos y frases comunes
Act of June agreement All-American Canal alleged amount approved April Army Article Attorney August Bronze Company Civilian Conservation Corps Colonel Commissioner completed Comptroller Congress construction engineer contracting officer contractor corporation Corps cost Court of Claims cubic yards December decided decision deducted defendant defendant's delay Department dredge entitled to recover excavation expense February February 27 filed findings of fact Ford Range furnished Government Hackfeld hardpan increased Indians Industrial Recovery Act Internal Revenue January John F Judge judgment July June 25 June 30 jurisdiction Kawneer King & King labor land-grant lands liquidated damages March material ment National Industrial Recovery Navy November October paid paragraph pay and allowances payment period petition plaintiff preferred stock Progress Administration quarters referred refund Reporter's Statement Republic of Hawaii request routes Secretary Section specifications Stat statute suit supervising architect temporary heat thereof tiff tion tract United
Pasajes populares
Página 58 - ARTICLE 3. Changes. — The contracting officer may at any time, by a written order, and without notice to the sureties, make changes in the drawings and/or specifications of this contract and within the general scope thereof. If such changes cause an increase or decrease in the amount due under this contract, or in the time required for its performance, an equitable adjustment shall be made and the contract shall be modified in writing accordingly.
Página 381 - The judicial power of the United States shall be vested in one Supreme Court, and such inferior courts as the Congress may from time to time ordain and establish.
Página 272 - ... that he will support the constitution of the United States, and that he doth absolutely and entirely renounce and abjure all allegiance and fidelity to every foreign prince, potentate, state, or sovereignty whatever, and particularly, by name, the prince, potentate, state, or sovereignty, whereof he was before a citizen or subject; which proceedings shall be recorded by the clerk of the court.
Página 387 - It is as much the duty of government to render prompt justice against itself in favor of citizens as it is to administer the same between private individuals.
Página 294 - Until Congress shall provide for the government of such islands all the civil, judicial and military powers exercised by the officers of the existing government in said islands shall be vested in such person or persons and shall be exercised in such manner as the President of the United States shall direct; and the President shall have power to remove said officers and fill the vacancies so occasioned.
Página 342 - No officer shall be discharged or dismissed from the service, except by order of the President, or by sentence of a general court-martial; and in time of peace no officer shall be dismissed, except in pursuance of the sentence of a court-martial, or in mitigation thereof.
Página 315 - To the extent of any interest therein of which the decedent has at any time made a transfer, or with respect to which he has...
Página 29 - ... unforeseeable causes beyond the control and without the fault or negligence of the Contractor, including, but not restricted to, acts of God, or of the public enemy, acts of the Government, in either its sovereign or contractual capacity, a,cts of another contractor in the performance of a contract with the Government, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather, or delays of subcontractors or suppliers due to such causes...
Página 242 - Except as otherwise specifically provided in this contract, all disputes concerning questions of fact arising under this contract shall be decided by the contracting officer subject to written appeal by the contractor within 30 days to the head of the department concerned or his duly authorized representative, whose decision shall be final and conclusive upon the parties thereto. In the meantime the contractor shall diligently proceed with the work as directed.
Página 478 - All material and work covered by progress payments made shall thereupon become the sole property of the Government, but this provision shall not be construed as relieving the Contractor from the sole responsibility for all...